1.Free Delivery within 48 hrs is applicable only for the products purchased from Ultron Commerce Pvt Ltd through the website [https://store.in.panasonic.com/].

 

2.Above timeline commitment is valid only for the following deliverable city municipal limits i.e. Bangalore, Chennai, Delhi, Gurgaon, Faridabad, Gautam Budh Nagar/Noida, Ghaziabad, Greater Noida, Hyderabad, Mumbai, Navi Mumbai, Thane, Greater Thane and Secunderabad. Any other city not eligible for the delivery.

 

3.There can be a possibility that the ordered product(s) are/is available in a different state/Warehouse of Ultron, in such a scenario the delivery time shall be greater than 48 hours.

 

4.Delivery terms are subject to business working days and business working hours of the Ultron.

 

5.Delivery is subject to state, national, local holiday(s) and any order issued by appropriate government/authority resulting in close down, curfew and lockdown etc.

 

6.Delivery timeline is subject to appointment time given by the Customer.

 

7.Delivery will depend upon the visiting hours applicable as per the society timings.

 

8.Delivery timeline is also subject to the “no entry time” of the respective city as prescribed by the road transport authority for plying commercial vehicle.

 

9.Loading & unloading constraints at the customer location such as absence of lift, small staircase etc. can delay the delivery timelines.

 

10.Delivery deadlines may get extended to a reasonable period if not met for reasons beyond our control, such as force majeure events as defined in terms and conditions.

 

11.Ultron reserves the right at any time, without prior notice and without assigning any reason whatsoever, to modify, vary, curtail, withdraw and extend the delivery timeline or to replace this timeline by another.

 

12.The decision of Ultron with regard to the above will be final.

 

13.The Customer specifically waives any claim pertaining to delay in delivery of Products. Our delivery partners reserve the right to restrict delivery to specific locations or delivery facilities.

 

14.Any dispute with regard to the Delivery timeline is subject to the jurisdiction of the courts of New Delhi only.

1.Eligible product installation shall be applicable only for the products purchased from Ultron Commerce Pvt. Ltd. through the website [https://store.in.panasonic.com/] within 24 hrs. from the delivery date & time.

 

2.Above timeline commitment is valid only for the following deliverable city municipal limits i.e. Bangalore, Chennai, Delhi, Gurgaon, Faridabad, Gautam Budh Nagar/Noida, Ghaziabad, Greater Noida, Hyderabad, Mumbai, Navi Mumbai, Thane, Greater Thane and Secunderabad. Any other city not eligible for the delivery.

 

3.Installation is subject to business working days and business working hours of Panasonic.

 

4.Upon delivery of the Product, the customer will receive a call from the Authorized Service Centre (ASC) to fix an appointment for installation. The customer may choose to assign a date of choice based on the customer’s requirement if it is more than 24 hours from the time of delivery of the product.

 

5.Installation timeline will start and will happen within 24hours from the time the call is received by the customer after delivery of the product to fix the appointment time. Timelines will also depend upon the appointment time given by the customer.

 

6.Panasonic will not be responsible for any delay if the phone number provided by the customer is not reachable, unanswered or is not correct.

 

7.Installation charges, as applicable, will be payable by the customer directly to the ASC representative(s).

 

8.Site readiness from the customer side would be required which include appropriate space, additional arrangements required to complete the installation such as power-point/MCB fitting or any other electrical work etc. Panasonic will not be responsible for any delay on the part of the customer in this regard.

 

9.If the installation site is found not to be appropriate by the ASC’s engineer, engineer will suggest a alternate site option for installation. However, customer’s demand will be addressed appropriately.

 

10.In case of abnormal location of installation, arrangements like ladder, staircase, tables etc. would be required and will be arranged by the customer only. This may lead to delay in installation.

 

11.If any additional material is required and the customer wants to procure by himself, delay in procurement may further delay the completion of installation.

 

12.Installation is subject to state, national, local & weekly market holiday(s) and any order issued by appropriate government/authority resulting in close down, curfew, lockdown etc.

 

13.Installation deadlines may get extended to a reasonable period, if not met for reasons beyond our control, such as force majeure events as defined in terms and conditions.

 

14.Panasonic reserves the right at any time, without prior notice and without assigning any reason whatsoever, to modify, vary, curtail, withdraw and extend the installation timeline or to replace this timeline by another.

 

15.The decision of Panasonic with regard to the above will be final.

 

16.Any dispute with regard to the timeline is subject to the jurisdiction of the courts of New Delhi only.

1. Cash Back & No Cost EMI offers (“Offer”) are hosted by Panasonic Life Solutions India Pvt. Ltd. on the website [https://store.in.panasonic.com/].

 

2. Cash Back offer is provided by ICICI Bank (ICICI Bank Limited), Standard Chartered Bank (SC), Bank of Baroda (BOB) on the Website.

 

3. Any person holding a valid Credit card issued by the ICICI Bank (ICICI Bank Limited), Standard Chartered Bank (SC), Bank of Baroda (BOB) are eligible to avail the Cash Back Offer & No Cost EMI offer is provided by AXIS Bank, Citibank, HSBC, Indusind Bank, Kotak, Standard Chartered Bank (SC), SBI, UBI, Bank of Baroda (BOB), ICICI Bank, Yes Bank & HDFC Bank Credit Cards.

 

4. Any person holding a valid Debit card issued by the ICICI Bank are eligible to avail the Cash Back Offer & Any person holding a valid Debit card issued by Axis Bank, Kotak, ICICI Bank & HDFC Bank Debit Card is eligible for No Cost EMI.

 

5. Cash Back & No Cost EMI Offers are not valid on corporate, cobranded or commercial Cards issued by any of the participating Bank.

 

6. Cash Back & No Cost EMI Offers are applicable only on purchase of selected Panasonic Product by Cardholder on availing Equated monthly payment option (NCEMI) on the Pinelabs payment gateway at the Website.

7. The Bank will continue to charge interest on No Cost EMI plans as per existing rates, the interest to be charged by the bank will be passed on to you as an upfront discount.

8. Cash Back & No Cost EMI Offers are NOT applicable on payment made by customers using any other payment option.

 

9. Cash Back offer is only applicable on 3 & 6 months EMI tenure transections for select products in these categories viz. LED, Refrigerator, Washing Machine, Air-conditioner, Microwave Oven & Vacuum Cleaner.

 

10. Cash Back offer is applicable on 3, 6, 9 & 12 months EMI tenure transections for select products in LED category only.

 

11. No Cost EMI Offer is applicable on 3, 6, 9 & 12 months based on the select Panasonic product categories.

 

12. Both Cash Back & No Cost EMI offers can be availed for the eligible product & eligible Debit / Credit Card.

 

13. This is a Limited period offer.

 

14. Cash Back is limited to the maximum amount capping allowed in the offer. Cash Back is depicted as a percentage of the Selling price or an absolute currency value with a maximum capping, the applicable Cash Back will be based on the lower of the 2 values.

 

15. In case the customer is buying multiple products in one cart which are eligible for Cash Back, then only the lowest Cash Back of all the eligible products will be accepted in the purchase & only once can the customer avail the Cash Back on one card in one month.

 

16. Cash Back offer applicability may also depend on the type/category of card which you are using. If in case, you are not able to avail the offer then you are requested to contact your issuing bank.

 

17. Cash Back Offer is valid within select cities only where product is deliverable as per Website.

 

18. Cash Back for all transactions will be credited to the cardholder's card account within 120 days (One Twenty) days from the end of the transaction month.

 

19. Cash Back Offer will not be applicable if the Cardholder or Ultron cancels the order and/or the Cardholder returns the Product and, in such a case, participation in the Offer will be deemed withdrawn. In such a scenario, only the net amount paid by the Cardholder will be refunded. In other words, the cashback will not be refunded and if paid will be taken back or adjusted by the Bank.

 

20. Cardholders are not bound in any way to participate in this Offer. Any participation is voluntary and the Offer is being made purely on a best effort basis.

 

21. Any person availing these Offers will be deemed to have accepted these Offer Terms.

 

22. Offer is by way of a special offer and nothing contained herein will prejudice or affect the terms and conditions of the Card member agreement with the Bank.

 

23. Offers are applicable till stocks last or the validity whichever is earlier.

 

24. Panasonic reserves the right at any time, without prior notice and without assigning any reason whatsoever, to modify, vary, curtail, withdraw and extend the offer or to replace, wholly or in part, this offer by another offer, whether similar to this offer or not.

 

25. The decision of Panasonic with regard to the offer is final.

 

26. Any dispute with regard to the offer is subject to the jurisdiction of the courts of New Delhi only.

 

27. EMI Option and eligibility is available at the sole discretion of the Bank/Banks. Refer T&C of the Bank for the same.

1.‘Ultron’ may offer discounts on MRP of the products being sold by ‘Ultron’ subject to ‘Ultron’s’ discretion.

1.Brand may offer benefits to the customer under Extended warranty purchase plans.

1.An existing customer of Panasonic product can raise a service request through the website by clicking on the applicable link pertaining to in-warranty / out-warranty repair or maintenance of their Panasonic products.